Legals August 8, 2018

Print Article

NOTICE OF LETTING Sealed proposals will be received by the City of Wallace at 703 Cedar Street, Wallace, ID 83873 - ATTN: KRISTINA LARSON, City Clerk until two o'clock p.m., on August 29, 2018 for the work of constructing an Eco-Block Retaining Wall for the Bank Street Wall Project located in Wallace, Shoshone County, ID. (ADDITIONAL INFORMATION CONTACT: JAMES ROLETTO, P.E. AT (208) 967-4232.) Plans, specifications, form of contract, proposal forms, and other information may be obtained, by request, from the City of Wallace at (208) 752-1147. This contract requires full compliance with Title VI of the Civil Rights Act of 1964, which protects persons from being denied the benefits of or excluded from participation in programs or activities; or subjected to discrimination based on race, color, national origin, sex, age, disability, Limited English Proficiency or economic status. The Contractor is encouraged to utilize the goods and services of disadvantaged firms in accomplishing the tasks or providing the services of this agreement, and to provide equal opportunity to all sub-bidders and suppliers. SHO LEGAL 2779 AD#214590 AUGUST 8, 11, 2018

NOTICE TO CREDITORS (I.C. 15-3-801) Case No. CV40-18-0325 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF SHOSHONE IN THE MATTER OF THE ESTATE OF James Eugene Hopkins Deceased NOTICE IS HEREBY GIVEN that Joann Kern has been appointed Personal Representative of the above named Estate. All persons having claims against the decedent or the Estate are required to present their claims within four (4) months after the date of the first publication of this Notice to Creditors, or said claims will be forever barred. Claims must be presented to the undersigned at the address indicated and filed with the Clerk of the Court. Dated this 18th day of July, 2018 /S/ Rebecca R. Eyman COYLE & WYTYCHAK ELDER LAW P.O. Box 1888 Coeur d'Alene, ID 83816-1888 Telephone (208) 765-3595 ISB No. 10353 SHO LEGAL 2958 AD#210860 JULY 25, AUGUST 1, 8, 2018

IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE THE COUNTY OF KOOTENAI NOTICE TO CREDITORS (I.C. 15-9-801) Case No. CV28-18-5149 In Re the Estate of: ROBERT LEE MCKINNON, Deceased. NOTICE IS HEREBY GIVEN that the undersigned has been appointed personal representative of the above-named decedent. All persons having claims against the decedent or the estate are required to present their claims within four (4) months after the first publication of this Notice or said claims will be forever barred. Claims must be presented to the undersigned at the address indicated, and filed with the Clerk of the Court. DATED: July 25, 2018 /s/ JENNIFER R. HAZELTON Personal Representative C/O Gregory L. Decker 1919 N. 3rd Street Coeur d Alene, ID 83814 (208) 667-9544 SHO LEGAL 2970 AD#212581 AUGUST 1, 8, 15, 2018

NOTICE OF TRUSTEE'S SALE - To be sold for cash at a Trustee's Sale on December 4, 2018, 09:00 AM at the In the Lobby Shoshone County Courthouse, 700 Bank Street, Wallace, ID 83873, the following described real property situated in Shoshone County, State of Idaho ("Real Property"): Lots 1, 2, 3, 4 and 5 in Block 15 of Ediams Mountain View Addition to Wallace, Shoshone County, State of Idaho, according to the Official and Recorded Plat thereof Commonly known as: 1005 Pearl Street, Wallace, ID 83873 William L Cunningham, as Trustor conveyed Real Property via a Trust Deed dated December 15, 2015, in favor of Mortgage Electronic Registration Systems, Inc. as nominee for Movement Mortgage, LLC, its successors and assigns as Beneficiary, in which Alliance Title & Escrow Corp. was named as Trustee. The Trust Deed was recorded in Shoshone County, Idaho, on December 17, 2015, as Instrument No. 483475, of Official Records. The Deed of Trust was assigned for value as follows: Assignee: Matrix Financial Services Corporation Assignment Dated: November 27, 2017 Assignment Recorded: December 4, 2017 Assignment Recording Information: Instrument No. 491605 Shelly M. Espinosa is the Successor Trustee pursuant to a Substitution of Trustee recorded in the office of the Clerk and Recorder of Shoshone, State of Idaho on June 7, 2018 at Instrument No. 494381, of Official Records. The Beneficiary has declared a default in the terms of said Deed of Trust due to Trustor failure to make monthly payments beginning December 1, 2017, and each month subsequent, which monthly installments would have been applied on the principal and interest due on said obligation and other charges against the property or loan. By reason of said default, the Beneficiary has declared all sums owing on the obligation secured by said Trust Deed immediately due and payable. The total amount due on this obligation is the principal sum of $131,036.36, interest in the sum of $4,519.55, escrow advances of $532.06, other amounts due and payable in the amount of $1,386.40, for a total amount owing of $137,474.37, plus accruing interest, late charges, and other fees and costs that may be incurred or advanced. The Beneficiary anticipates and may disburse such amounts as may be required to preserve and protect the property and for real property taxes that may become due or delinquent, unless such amounts of taxes are paid by the Trustor. If such amounts are paid by the Beneficiary, the amounts or taxes will be added to the obligations secured by the Deed of Trust. Other expenses to be charged against the proceeds of this sale include the Trustee's fees and attorney's fees, costs and expenses of the sale, and late charges, if any. Beneficiary has elected, and has directed the Trustee to sell the above described property to satisfy the obligation. The sale is a public sale and any person, including the Beneficiary, may bid at the sale. The bid price must be paid immediately upon the close of bidding in cash or cash equivalents (valid money orders, certified checks or cashier's checks). The conveyance will be made by Trustee's Deed, without any representation or warranty, including warranty of title, express or implied, as the sale is made strictly on an as-is, where-is basis, without limitation, the sale is being made subject to all existing conditions, if any, of lead paint, mold or other environmental or health hazards. The Trustor, successor in interest to the Trustor, or any other person having an interest in the property, or any person named in IRC 45-1506, has the right, at any time prior to the Trustee's Sale, to pay to the Beneficiary, or the successor in interest to the Beneficiary, the entire amount then due under the Deed of Trust and the obligation secured thereby (including costs and expenses actually incurred and attorney's fees) other than such portion of the principal as would not then be due had no default occurred and by curing any other default complained of herein that is capable of being cured by tendering the performance required under the obligation or to cure the default, by paying all costs and expenses actually incurred in enforcing the obligation and Deed of Trust with Successor Trustee's and attorney's fees. In the event that all defaults are cured the foreclosure will be dismissed and the foreclosure sale will be canceled. The scheduled Trustee's Sale may be postponed by public proclamation up to 30 days for any reason. If the Trustee is unable to convey title for any reason, the successful bidder's sole and exclusive remedy shall be the return of monies paid to the Successor Trustee and the successful bidder shall have no further recourse. The above Trustor are named to comply with IRC 45-1506(4)(a). No representation is made that they are, or are not, presently responsible for this obligation. This is an attempt to collect a debt and any information obtained will be used for that purpose. Dated this 25th day of July, 2018. Shelly M. Espinosa Substitute Trustee 376 East 400 South, Suite 300, Salt Lake City, UT 84111 Telephone: 801-355-2886 Office Hours: Mon.-Fri., 8AM-5PM (MST) File No. 52781 SHO LEGAL 2972 AD#31291 AUGUST 1, 8, 15, 22, 2018

KINGSTON WATER DISTRICT 2018-2019 Budget Proposed INCOME Connection Fees & Facility Income 154,695 Property & Sales Tax 8,563 Interest Income 3,962 Carry-over 3,000 TOTAL INCOME 170,220 EXPENDITURES Capital Improvements 0 Communications 1,500 Directors' Fees 6,000 Dues & Subscriptions, License & Permits 2,250 Shop Supplies / General Expense 750 Insurance 4,800 Legal & Professional 7,500 Loan Payment 41,545 Maintenance & Repairs 18,678 Miscellaneous 500 Office Expense 2,750 Payroll Expense 4,625 Postage & Shipping 1,575 Rent 2,250 Retirement 6,247 Salary & Wages 51,500 Water Treatment 1,000 Snow Plowing 400 Software & Tech Support 2,750 Training & Travel 3,000 Utilities 9,500 Water Tests 1,100 TOTAL EXPENDITURES 170,220 NOTICE OF PUBLIC HEARING: The aforementioned budget will be considered at the regular meeting of the Kingston Water District on August 20, 2018 at 6:30 PM, at the District Office, 42784 Silver Valley Road, Kingston, Idaho. All interested parties are invited to attend and show cause, if any, why the said budget should not be adopted. The budget may be examined during regular posted business hours. Any person needing special accomodations to participate in the above meeting should contact the Kingston Water District Office seven (7) days prior to the meeting at (208) 682-3892. SHO LEGAL 2965 AD#211863 AUGUST 8, 2018

INVITATION TO BID NOTICE TO CONTRACTORS: Sealed bid proposals will be received - BY SHOSHONE MEDICAL CENTER FOR: SHOSHONE MEDICAL CENTER FAMILY MEDICINE REMODEL 858 Commerce Drive Smelterville, ID 83868 AS FOLLOWS: General Construction Prime Bids for this project shall be received as follows: * BIDS shall be due Wednesday, August 22, 2018 at 3:30 p.m. at the SHOSHONE MEDICAL CENTER, 25 JACOBS GULCH, KELLOGG, Idaho. * PRE-BID CONFERENCE: shall be Wednesday, August 15, 2018 at 1:30 p.m. at 858 COMMERCE DRIVE, SMELTERVILLE, ID. * Bids shall be publicly opened and read aloud at the date and time noted above * Plans and specifications, bid forms, forms of agreement, etc., may be obtained by bona fide general bidders, and bona fide mechanical, electrical and plumbing sub-bidders, and suppliers at www.longwelltrappplanroom.com. Complete bidding documents for this project are available in electronic form only, by downloading the documents (at no charge) or by purchasing hard copy documents (at bidders expense) from the plan room noted above. To be added to the official plan holders list and insure notification of addenda, bidders must register at the plan room noted above. The Architect and Owner will not be responsible for partial sets of documents obtained from reprographics companies or plan centers. Any and all errors or omissions resulting from the failure of the General Contractor, Subcontractor or material supplier to become familiar with the documents in their entirety will be corrected at the Contractor's expense. Questions regarding this Notice of Advertisement for bids shall be directed to the office of Longwell + Trapp Architects, 8382 N. Wayne Dr, Ste. 204, Hayden, ID 83835. Phone number of Architect is (208) 772-0503, Fax number is (208) 772-6705. Project Architect: Cory Trapp, AIA Bid forms, Bidders instructions, drawings and specifications may be examined at the following locations: - www.longwelltrappplanroom.com - Abadan Plan Room, Spokane, Washington - Spokane Regional Plan Center, Spokane, Washington - Associated Builders & Contractors, Spokane, Washington - Longwell + Trapp Architects Idaho law requires that all bidders have an Idaho Public Works Contractor's License, as provided for by the Public Works Contractors License Act. Bids must be made upon the form furnished, must be accompanied by a bid bond or other surety in the amount of 5% of the total bid amount, and cannot be withdrawn until thirty (30) days after the above stated times of opening. The SHOSHONE MEDICAL CENTER (SMC) reserves the right to reject any and all bids, to waive any informalities and to award the bid to the responsive bidder that SMC deems is in the best interest of SMC. In the event that SMC elects to award the bid to other than the lowest responsive bidder, SMC will declare its reasons on the record and communicate those reasons in writing to all person having submitted a competing bid. If there are two or more identical responsive bids from which SMC elects to make the selection, SMC shall have the discretion to award the bid in any manner deemed fair and equitable and in the best interest of SHOSHONE MEDICAL CENTER. SHO LEGAL 2782 AD#214615 AUGUST 8, 15, 2018

SUMMONS FOR PUBLICATION Case No.: CV40-18-0252 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF SHOSHONE DITECH FINANCIAL LLC, Plaintiff, vs. THE ESTATE OF RONALD W. DORCHUCK; LORNA M. DORCHUCK (DECEASED) And The Unknown Heirs, Assigns, An Devisees Of LORNA M. CORCHUCK; STERLING SAVINGS BANK; MARGIE DORCHUCK; and Does I through XX, as individuals with an interest in the property which may commonly be known as: 637 Division Street, Kellogg, ID 83837, Defendants. TO: ALL DEFENDANTS NOTICE: YOU HAVE BEEN SUED BY THE ABOVE-NAMED PLAINTIFF. The nature of the claim against you is for, among other things, judicial foreclosure of the real property located at 637 Division Street, Kellogg, Idaho 83837. The Court may enter judgment against you without further notice unless you respond. READ THE INFORMATION BELOW. YOU ARE HEREBY NOTIFIED that in order to defend this lawsuit, an appropriate written response must be filed with the above-designated Court, 700 Bank Street, Suite 120, Wallace, ID 83873, within twenty-one (21) days after service of this Summons on you. If you fail to so respond, the Court may enter judgment against you as demanded by the Plaintiff in the Complaint. A copy of the Summons and Complaint can be obtained by contacting either the Clerk of the court at the Shoshone County Courthouse, 700 Bank Street, Suite 120, Wallace, Idaho 83873, 752-1264, or the attorney for the Plaintiff, David M. Swartley, McCarthy & Holthus, LLP, 702 W. Idaho Street, Suite 1100, Boise, Idaho 83702, (208) 947-7264. If you wish to seek the advice or representation by an attorney in this matter, you should do so promptly so that your written response, if any, may be filed in time and other legal rights protected. An appropriate written response requires compliance with Rule 10(a)(1) and other Idaho Rules of Civil Procedure and shall also include: 1. The title and number of this case. 2. If your response is an Answer to the Complaint, it must contain admissions or denials of the separate allegations of the Complaint and other defenses you may claim. 3. Your signature, mailing address, and telephone number, or the signature, mailing address, and telephone number of your attorney. 4. Proof of mailing or delivery of a copy of your response to Plaintiff's attorney, as designated above. To determine whether you must pay a filing fee with your response, contact the Clerk of the above-named court. Dated this 17th day of July, 2018 Clerk of the District Court By: /S/ Gail Elliott, Deputy SHO LEGAL 2951 AD#210386 JULY 25, AUGUST 1, 8, 15, 2018

SHOSHONE COUNTY FIRE PROTECTION DISTRICT #3 PROPOSED 2018-2019 BUDGET NOTICE IS HEREBY GIVEN that the Shoshone County Fire Protection District #3 of Mullan, Idaho will hold a public hearing for consideration of the proposed budget for the fiscal year 2018-2019. Said hearing is to be held at the District #3 Garage, 461 Friday Ave., Mullan, Idaho at 6:00 P.M. on August 23, 2018. All interested parties are invited to appear and offer testimony concerning the proposed budget. REVENUE Taxes $ 37,700 Other Revenue $ 5,000 Total Revenues $ 37,700 EXPENDITURES District Operations $ 8,000 Equipment $ 8,200 Repairs $ 8,000 Meetings/Conventions $ 700 Telephone $ 3,600 Utilities $ 3,600 Co-op (City of Mullan) $ 3,600 Utilities (City of Mullan) $ 2,000 Total Expenditures $ 37,700 SHO LEGAL 2973 AD#213707 AUGUST 8, 15, 2018

PUBLIC NOTICE OF INTENT TO PROPOSE OR PROMULGATE NEW OR CHANGED AGENCY RULES The following agencies of the state of Idaho have published the complete text and all related, pertinent information concerning their intent to change or make the following rules in the latest publication of the state Administrative Bulletin. The proposed rule public hearing request deadline is August 15, 2018, unless otherwise posted. The proposed rule written comment submission deadline is August 22, 2018, unless otherwise posted. (Temp & Prop) indicates the rulemaking is both Temporary and Proposed. (*PH) indicates that a public hearing has been scheduled. IDAPA 07 -DIVISION OF BUILDING SAFETY PO Box 83720, Meridian, ID 83642 07-0206-1702, Rules Concerning Idaho State Plumbing Code. Revises certain sections of the 2017 Idaho State Plumbing Code to require an air gap or backflow prevention device on a potable water supply to beverage dispensers or coffee machines; allows water closets to act as cleanouts and requires installation of exterior, two-way cleanouts; replaces the first hour ratings in table 501.1(1) with ratings calculated using the U.S. Department of Energy's revised ratings method. 07-0501-1801, Rules of the Public Works Contractors License Board. Defines an individual qualified by examination (QI) designation; determines the "reasonable length of time" a contractor's license will remain in force; and clarifies that notice that a contractor's QI has ceased to be connected with the contractor must be provided on forms prescribed by the administrator. 07-0701-1703, Rules Governing Installation of Heating, Ventilation, and Air Conditioning Systems. Allows apprentices to take the journeyman exam before completing four years' work experience and allows apprentices who successfully complete a Board-approved, full-time, one-year training course to receive credit for up to one year of work experience. IDAPA 08 - STATE BOARD OF EDUCATION AND DEPARTMENT OF EDUCATION PO Box 83720, Boise ID 83720-0027 08-0202-1801, Rules Governing Uniformity. Makes certification and endorsement revisions for school nurse, teacher librarian, teacher leader, gited and talented, English, online teacher, and literacy; defines "clinical experience"; adds new endorsements for middle school social studies and science; addresses the use of continuing education units toward a certificate renewal by pupil service staff certificate holders who also hold a license through IBOL. 08.02.03 - Rules Governing Thoroughness 08-0203-1801, Incorporates by reference the updated Idaho Special Education Manual. 08-0203-1805, Removes obsolete references to Annual Measurable Achievement Objectives (AMAOs). IDAPA 10 -BOARD OF PROFESSIONAL ENGINEERS AND PROFESSIONAL LAND SURVEYORS 1510 Watertower St, Meridian, ID 83642 *10-0101-1801, Rules of Procedure. (*PH) Implements SB 1252 by repealing examination failure requirements, allowing for early testing for professional examinations, and adding a new category for discontinued certificates of authorization. *10-0102-1801, Rules of Professional Responsibility. (*PH) Requires professional land surveyors to notify affected adjacent landowners and the Board prior to setting a monument that represents a material discrepancy with another monument for the same property corner and potentially clouding the title of private land. IDAPA 12 -DEPARTMENT OF FINANCE PO Box 83720 Boise, ID 83720-0031 12-0108-1801, Rules Pursuant to the Uniform Securities Act (2004). Removes an exemption for a federal securities issuer that no longer exists; addresses recent changes in uniform securities examinations as adopted by both federal and state securities regulators. IDAPA 16 -DEPARTMENT OF HEALTH AND WELFARE PO Box 83720, Boise, ID 83720-0036 16-0309-1809, Medicaid Basic Plan Benefits. (Temp & Prop) PCS paraprofessional provider qualifications are being be updated for school-based services to align with community paraprofessional PCS provider qualifications. (eff. 8-1-18)T *16-0310-1801, Medicaid Enhanced Plan Benefits. (*PH) (Temp & Prop) Allows Medicaid to enroll dual eligibles who have not elected to enroll in the coordinated MMCP into a Medicaid Managed Long-Term Services and Supports program, which will administer and coordinate Medicaid benefits. (eff. 10-1-18)T IDAPA 20 -IDAHO DEPARTMENT OF LANDS 3284 W. Industrial Loop, Coeur d'Alene, ID 83815 20-0401-1801, Rules Pertaining to Forest Fire Protection. Incorporates by reference the spark arrester standards established in 2012; adds required sections; updates and adds definitions; updates fire tool requirements and new fire protection requirements for forest operation activities involving cable logging operations and the use of metal tracked harvesters to include on-site water supply, fire watch service and operation area fire prevention practices. IDAPA 24 -BUREAU OF OCCUPATIONAL LICENSES PO Box 83720, Boise, ID 83720-0065 24-0101-1801, Rules of the Board of Architectural Examiners. (Temp & Prop) Implements HB 458 by updating and streamlining processes to make it easier for licensees and those seeking licensure to obtain one; removes a 30-day application deadline; eliminates unnecessary and obsolete language. (eff. 7-1-18)T 24-1501-1801, Rules of the Idaho Licensing Board of Professional Counselors and Marriage and Family Therapists. (Temp & Prop) Establishes education requirements, reduces costs and barriers for licensure; allows an individual to work under supervision while completing licensure requirements; accepts the Commission on Accreditation for Marriage and Family Therapy Education (COAMFTE) graduate programs as meeting all education requirements; increases flexibility to complete both practicum and supervised experience hours, which reduces tuition and supervision costs for applicants. (eff. 7-1-18)T IDAPA 34 -OFFICE OF THE SECRETARY OF STATE PO Box 83720, Boise, ID 83720-0080 *34-0602-1801, Rules Governing the Electronic Recording of Plats, Records of Survey, and Corner Records. (*PH) New chapter implements consistent standards for electronically filing and recording plats, records of survey, and corner records in county courthouses. IDAPA 35 -IDAHO STATE TAX COMMISSION PO Box 36, Boise, ID 83722-0410 35-0101-1801, Income Tax Administrative Rules. Clarifies Commission's application of Federal retroactive provisions and that uncodified provisions of federal law are included when calculating Idaho taxable income; new rule tells how to report federal section 965 deemed repatriation income on the Idaho return; adds 2018 tax bracket; limits and exempts certain contributions and earnings for non-qualified withdrawals from college savings to what was previously exempt; increases deductions for adoption expenses; adds the amount of guaranteed payments that are sourced as compensation for services for 2018; lists the corporate tax rates for 2001 through 2018; adds the new Idaho child tax credit; changes the date the withholding reconciliation return must be filed; modifies the time period that a taxpayer has to notify the Tax Commission of a change in federal taxable income or in tax paid to another state; deletes obsolete rules. 35-0102-1801, Idaho Sales and Use Tax Administrative Rules. Clarifies that parts installed in non-resident aircraft are exempt from sales tax if those parts are installed by a FAA approved repair station, even if the repair is paid for under a warranty agreement; removes the 5% tax schedule from the sales tax tables. 35-0105-1801, Idaho Motor Fuel Tax Administrative Rules. Clarifies which vehicles can use dyed diesel pursuant to 63-2425, Idaho Code. IDAPA 52 -IDAHO STATE LOTTERY COMMISSION PO Box 6537, Boise, ID 83707-6537 52-0103-1801, Rules Governing Operations of the Idaho State Lottery. Moves the Idaho Lottery to an automated balancing functionality by eliminating the use of Drawing Managers to audit and balance draws from the online game drawing procedure, a function that will be obsolete to industry practice and standard going forward. IDAPA 58 -DEPARTMENT OF ENVIRONMENTAL QUALITY 1410 N. Hilton, Boise, ID 83706-1255 58.01.01 - Rules for the Control of Air Pollution in Idaho *58-0101-1801, (*PH) Updates and clarifies certain air quality permitting provisions including minor clarifications for sources seeking air quality permits or exemptions from permitting; resolves inconsistencies in rule language; removes outdated references: adds provisions for renewing operating permits. Comment by 9/5/2018 *58-0101-1803, (*PH) Allows farmers to pay the required burn fees after crop burning instead of prior to burning; streamlines DEQ administrative processes for permit registration and fee collections. Comment by 9/5/2018 *58-0101-1804, (*PH) Updates and adopts amendments to the Clean Air Act federal regulations that are incorporated by reference. Comment by 9/5/2018 58-0102-1703, Water Quality Standards. Designates domestic water supply as a beneficial use in 27 water bodies where the Safe Drinking Water Information System indicates an active surface water intake and where domestic water supply is not currently designated. Comment by 8/31/2018 58-0105-1801, Rules and Standards for Hazardous Waste. Updates and adopts amendments to the Resource Conservation and Recovery Act federal regulations that are incorporated by reference. Comment by 8/29/2018 NOTICES OF ADOPTION OF TEMPORARY RULE ONLY IDAPA 24 -BUREAU OF OCCUPATIONAL LICENSES 24-2801-1801, Rules of the Barber and Cosmetology Services Licensing Board (eff. 7-2-18)T IDAPA 35 -IDAHO STATE TAX COMMISSION 35-0102-1802, Idaho Sales and Use Tax Administrative Rules (eff. 1-1-18)T NOTICES OF PROCLAMATION IDAPA 13 -IDAHO FISH AND GAME COMMISSION / DEPT OF FISH AND GAME 13.01.11 -Rules Governing Fish 13-0111-1802AP -Notice of Amended Proclamation 13-0111-1803AP -Notice of Amended Proclamation 13-0111-1804 -Notice of Proclamation Please refer to the Idaho Administrative Bulletin August 1, 2018, Volume 18-8, for the notices and text of all rulemakings, proclamations, negotiated rulemaking and public hearing information and schedules, executive orders of the Governor, and contact information. Issues of the Idaho Administrative Bulletin can be viewed at www.adminrules.idaho.gov/ Office of the Administrative Rules Coordinator, Dept. of Administration, PO Box 83720, Boise, ID 83720-0306 Phone: 208-332-1820; Email: rulescoordinator@adm.idaho.gov SHO LEGAL 2968 AD#212382 AUGUST 8, 2018

NOTICE OF SHERIFF'S SALE Case No.: CV-2017-252 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF SHOSHONE U.S. BANK NATIONAL ASSOCIATION, NOT IN ITS INDIVIDUAL CAPACITY, BUT SOLELY AS LEGAL TITLE TRUSTEE FOR BCAT 2016-18TT, Plaintiff, vs. JESSE R. REED (Deceased) and the Unknown Heirs, Assigns and Devisees of JESSE R. REED; KARISA REED; DOES I through XX, as individuals with an interest in the property legally described as: LOT 14, BLOCK 10 WALLACE, ACCORDING TO THE OFFICIAL AND RECORDED PLAT THEREOF, RECORDS OF SHOSHONE COUNTY, STATE OF IDAHO, Which may commonly be known as: 314 Pine St Wallace, ID 83873 Defendants. Under and by virtue of an Order for Sale of Foreclosure executed on March 7, 2018 and entered with the Court on March 13, 2018 and Writ of Execution issued on June 5, 2018 out of and under the seal of the above-entitled Court on a Judgment and Decree of Foreclosure recovered in said Court in the above-entitled action on the 13th day of March, 2018, in favor of the above-named Plaintiff, I am commanded and required to proceed to notice for sale to sell at public auction the real property described in said Order for Sale of Foreclosure and Writ of Execution and to apply the proceeds of such sale to the satisfaction of said Judgment and Decree of Foreclosure with interest thereon and my fees and costs. The property directed to be sold is situate in Shoshone County, State of Idaho, and is described as follows, to wit: LOT 14, BLOCK 10 WALLACE, ACCORDING TO THE OFFICIAL AND RECORDED PLAT THEREOF, RECORDS OF SHOSHONE COUNTY, STATE OF IDAHO. The above-described property is commonly known as 314 Pine St, Wallace, ID 83873. NOTICE IS HEREBY GIVEN that on the 29th day of August, 2018, at the hour of 2:00 o'clock p.m. of said day, in the Main Lobby of the Shoshone County Courthouse, 700 Bank Street, Wallace, County of Shoshone, State of Idaho, I will attend, offer and sell at public auction all or so much of the above-described property thus directed to be sold as may be necessary to raise sufficient funds to pay and satisfy the Judgment and Decree of Foreclosure as set out in said Order for Sale of Foreclosure to the highest bidder therefore in lawful money. The time period for redemption of the above property is six (6) months from the date of sale herein. DATED this 31st day of July, 2018. *** Darrell Michael Gunderson Sheriff of Shoshone County By: Melissa O'Connell Deputy Sheriff SHO LEGAL 2783 AD#214978 AUGUST 8, 15, 22, 2018

NOTICE TO CREDITORS Pursuant to: I.C. 15-3-801 CASE NO: CV40-18-341 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF SHOSHONE In the Matter of the Estate of: MICHAEL LEE SAGDAL DOD: 06/08/2018 Decedent. NOTICE IS HEREBY GIVEN that ANNA BERGER, has been appointed Personal Representative of the above named estate. All persons having claims against the above- named Decedent is required to present their claims, with a description of all security interests and other collateral, if any, held by each creditor with respect to such claim, within four months after the date of the first publication of this notice or said claims will be forever barred. Claims must be presented to ANNA BERGER, Personal Representative of the estate, c/o SILVER VALLEY LAW , LLC, PO Box 633, Osburn, Idaho, 83849, electronic service via email: office@silvervalleylaw.com, and filed with the Court to be valid. DATED this 31st day of July, 2018. /S/ KEISHA L. OXENDINE Attorney for Personal Representative SHO LEGAL 2784 AD#214995 AUGUST 8, 15, 22, 2018

NOTICE OF TRUSTEE'S SALE At 10:00 o'clock A.M. (recognized local time) on November 07, 2018, in the Office of First American Title Company, located at, 2 E. Mullan, Kellogg, Idaho, First American Title Company as Trustee, will sell at public auction, to the highest bidder, for cash, in lawful money of the United States, all payable at the time of sale, the following described real property, situated in Shoshone County, Idaho, and described as follows, to-wit: All Of Lot 12 Block 2 Excepting Therefrom The Northerly 33 Feet, Of The Townsite Of Smelterville, Shoshone County, State Of Idaho According To The Official Recorded Plat Thereof Information concerning the foreclosure action may be obtained from the Trustee, whose telephone number is (208) 785-2515. According to the Trustee's records, the street address of 206 Northview, Smelterville, Idaho 83868 is sometimes associated with said property. Said sale will be made without covenant or warranty regarding title, possession, or encumbrances to satisfy the obligations secured by and pursuant to the power of sale conferred in the Deed of Trust Including Due-On-Sale Rider executed by, Jamie Kae Sedlmayer, an unmarried woman as Grantor(s), First American Title Company, as Trustee, for the benefit and security of, Lisa Eaton, a Married woman and Janna Herdt, an unmarried woman, as Beneficiary; said Deed of Trust Including Due-on-Sale Rider was recorded February 16, 2018 as Shoshone County Recorder's Instrument No. 492655. The default for which this sale is to be made is as follows: 1. Failure to make the monthly payment of $850.00 plus a monthly escrow fee of $4.00 for a total monthly payment of $854.00 due for the 15th day of March 2018 and a like sum of $854.00 due for the 15th day of each and every month thereafter. 2. Failure to make the balloon payment in the amount of $3,880.00 due for the 6th day of April 2018 The above Grantor(s) are named to comply with Section 45-1506(4)(a), Idaho Code. No representation is made that they are, or are not, presently responsible for this obligation. As of June 19, 2018 there is due and owing on the loan an unpaid principal balance of $38,470.00, accrued interest in the amount of $674.54 for a total amount due of $39,144.54. Interest continues to accrue on the Note at the default rate of 5% per annum with a per diem rate of $5.27 after June 19, 2018. All delinquencies are now due together with any late charges, advances to protect the security, and fees and costs associated with this foreclosure. The Beneficiary elects to sell or cause said property to be sold to satisfy said obligation. DATED July 2, 2018 FIRST AMERICAN TITLE COMPANY By: /s/ Kaitlin Ann Gotch, Trust Officer SHO LEGAL 2937 AD#208630 JULY 18, 25, AUGUST 1, 8, 2018

NOTICE OF CALL FOR BIDS NOTICE IS HEREBY GIVEN that the Board of Trustees of School District No. 393 will receive sealed bids for the purpose of supplying milk for the Lunch Program for the 2018/2019 school year, ending June 30, 2019. Bidder must deliver milk to Silver Hills Elementary School and Wallace Jr./Sr. High School. Bids will be needed per 1/2 pint carton homogenized, per 1/2 carton 1%, per 1/2 carton 2%, and per 1/2 pint carton non-fat chocolate. * Bids will be accepted at the Office of the Superintendent of Schools, located at 501 Western Ave., Silverton, Idaho. Bids may be mailed to Dr. Robert Ranells, Superintendent, PO Box 267 Silverton, Idaho 83867. * All bids must be plainly marked "BID" on the outside of the envelope. * All bids must be exclusive of State and Federal taxes. * Bids must be in the School District Office by 12:00 noon, Monday, August 20, 2018, at which time they will be tabulated to be considered by the Board of Trustees. The Board of Trustees reserves the right to accept the bid deemed best or reject any and/or all bids and to waive any technicality. Dated this 31st day of July, 2018 Beatrice Conley, Clerk Wallace School District No. 393 SHO LEGAL 2780 AD#214603 AUGUST 8, 15, 2018

NOTICE OF CALL FOR BIDS NOTICE IS HEREBY GIVEN that the Board of Trustees of School District No. 393 will receive sealed bids for the purpose of supplying gasoline and diesel fuel for the buses, driver education vehicle, and maintenance department vehicles for the 2018-2019 school year, ending June 30, 2019. ALL BIDS SHOULD BE EXEMPT OF ALL APPROPRIATE TAXES. Bids prices must be as of August 20, 2018. The district will use approximately 15,000 gallons of gasoline during this time period. * Bids will be accepted at the Office of the Superintendent of Schools, located at 501 Western Ave., Silverton, Idaho 83867. Bids may be mailed to Dr. Bob Ranells, Superintendent, PO Box 267, Silverton, Idaho 83867. * All bids must be plainly marked "BID" on the outside of the envelope. * The supplier, upon request, must be able to show verification of any or all fluctuations in said bid price that occurs during the 2018/2019 school year. The Board of Trustees reserves the right to terminate the arrangement for supplying gasoline if any price increase is not approved. * Bids must be in the Office of the Superintendent of Schools by 12:00 noon, Monday, August 20, 2018, at which time they will be tabulated to be considered by the Board of Trustees. The Board of Trustees reserves the right to accept the bid deemed best or reject any and/or all bids and to waive any technicality. Dated this 31st day of July, 2018. Beatrice Conley, Clerk Wallace School District No. 393 SHO LEGAL 2781 AD#214606 AUGUST 8, 15, 2018

CITY OF WARDNER NOTICE OF PUBLIC HEARING NOTICE IS HEREBY GIVEN that a public hearing will be held at the Wardner City Hall, 649 Main Street, at 6:00 p.m. on Wednesday, August 8, 2018, to consider the proposed budget for the fiscal year October 1, 2018, to September 30, 2019. Interested persons may appear and show cause, if any, why said proposed budget should not be adopted. Actual Budget Current Budget Expenditures: FY16-17 FY17-18 FY17-18 FY18-19 General Fund $ 64,195 $60,361 $ 72,572 $58,952 Street Fund 70,376 31,481 30,559 34,350 Insurance 3,084 3,084 3,379 3,440 Totals $137,655 $94,926 $106,510 $96,742 Revenue: Property Taxes $ 59,399 $61,149 $ 45,562 $62,965 Intergovernmental 31,246 27,430 22,635 30,283 MSA Interest 13 12 6 10 Other Income 6,285 1,675 4,341 3,484 Carry Over 40,712 4,660 33,966 -- Totals $137,655 $94,926 $106,510 $96,742 Details are available by contacting the City Clerk, Linda Wombolt. SHO LEGAL 2971 AD#212682 AUGUST 1, 8, 2018

Print Article

Read More Legals

Legals November 14, 2018

November 14, 2018 at 1:30 am | PUBLIC SUMMONS IN THE DISTRICT COURT OF THE STATE OF WASHINGTON IN AND FOR THE COUNTY OF ASOTIN CREDIT BUREAU OF LEWISTON CLARKSTON, INC., a Washington Corporation, Plaintiff, CASEY R. WINCHEL, Defen...

Read More

Legals November 10, 2018

November 10, 2018 at 1:30 am | NOTICE OF TRUSTEE'S SALE NOTICE OF TRUSTEE'S SALE - To be sold for cash at a Trustee's Sale on January 22, 2019, 09:00 AM at the In the Lobby Shoshone County Courthouse, 700 Bank Street, Wallace, ID ...

Read More

Legals November 7, 2018

November 07, 2018 at 1:30 am | PUBLIC SUMMONS IN THE DISTRICT COURT OF THE STATE OF WASHINGTON IN AND FOR THE COUNTY OF ASOTIN CREDIT BUREAU OF LEWISTON CLARKSTON, INC., a Washington Corporation, Plaintiff, CASEY R. WINCHEL, Defen...

Read More

Legals November 3, 2018

November 03, 2018 at 1:30 am | NOTICE OF TRUSTEE'S SALE NOTICE OF TRUSTEE'S SALE - To be sold for cash at a Trustee's Sale on January 22, 2019, 09:00 AM at the In the Lobby Shoshone County Courthouse, 700 Bank Street, Wallace, ID ...

Read More

Contact Us

(208) 752-1120
620 E Mullan Ave.
P.O. Box 589
Osburn, Idaho 83849

©2018 Shoshone News Press Terms of Use Privacy Policy
X